equal protection provision of the Fourteenth Amendment because there might be other instances to which it might be equally well applied. Keokee Coke Cc. v. Taylor, 224.
31. Equal protection of the law; validity of Virginia statute providing method of payment of employés of certain industries.
Section 3 of Chapter 391, Virginia Laws of 1888, reënacting the act of 1887 aimed at the evil of payment of labor in orders redeemable only at the employers' shops and forbidding certain classes of em- ployers of labor to issue any order for payment thereto unless pur- porting to be redeemable for its face value in lawful money of the United States, is not an unconstitutional denial of equal protection of the law because it does not apply to other classes of employers who also own shops and pay with orders redeemable in mer- chandise. Ib.
32. Equal protection of the law; classification; reasonableness of; railroads and receivers of railroads.
A state police statute requiring railroad companies to use a specified safety device is not unconstitutional as denying equal protection of the laws because it does not affect receivers operating railroads; in view of the temporary and special character of a receiver's manage- ment the classification is reasonable and proper. Atlantic Coast Line v. Georgia, 280.
33. Equal protection of the law; classification; reasonableness; effect of provision on acts regulating judicial procedure.
A classification which is based on the distinction between that which is ordinary and that which is extraordinary is reasonable and not repugnant to the equal protection provision of the Fourteenth Amendment which only restrains acts regulating judicial procedure so transcending the limits of classification as to cause them to con- flict with the fundamental conceptions of just and equal legislation. Missouri Pacific Ry. Co. v. Larabee, 459.
34. Equal protection of the law; validity of state statute imposing attorney's fee in mandamus proceedings against party refusing to obey writ. A state statute imposing reasonable attorneys' fees in actual mandamus proceedings against the party refusing to obey a peremptory writ is not repugnant to the equal protection clause of the Fourteenth Amendment either because it does not apply to other proceedings or because it is not reciprocal. The classification is not unreason- able; and so held as to the statute to that effect of Kansas involved in this case and as herein applied. Ib.
35. Equal protection of the law; effect to deny, of Tennessee statute of 1865 relative to inheritance by issue of slave marriages.
The statute of Tennessee of 1865, c. 40, § 8, declaring that children of slave marriages should be legitimately entitled to inherit, as it has been construed by the highest court of that State as not extending the right of inheritance beyond lineal descendants of the parents, is not unconstitutional under the equal provision clause of the Fourteenth Amendment. Jones v. Jones, 615.
See SUPRA, 11, 12, 18;
INTERSTATE COMMERCE, 35.
36. Full faith and credit; contracts; obligation on courts.
Under the full faith and credit clause of the Federal Constitution the courts of one State are not bound to declare a contract, which was made in another State and modified a former contract, illegal be- cause it would be illegal under the law of the State where the original contract was made and of which neither of the parties is a resident or citizen. New York Life Ins. Co. v. Head, 149, 166.
37. Full faith and credit to which judgment of one State entitled in courts of another.
If the court rendering the judgment had jurisdiction of the subject- matter and the parties, the merits of the controversy are not open for reinvestigation in the courts of another State; but, under the full faith and credit clause of the Federal Constitution and § 905, Rev. Stat., the latter must give the judgment such credit as it has in the State where it was rendered. Roller v. Murray, 738.
38. Full faith and credit; effect of denial by court rendering judgment of due process of law.
The proper method of obtaining a review of the Federal question ad- versely decided by the state court is by writ of error to this court under § 237, Judicial Code, and not by collaterally attacking the judgment on the ground that it denies due process of law when it is invoked in the courts of another State. Ib.
39. Property rights; effect to take, of provision of Hepburn Act requiring owner of oil carrying pipe line to become common carrier.
Requiring a person engaged in interstate transportation of oil by pipe lines to become a common carrier does not involve a taking of private property, and the provision in the Hepburn Act to that effect is not unconstitutional under the Fifth Amendment. The Pipe Line Cases, 548.
See SUPRA, 19, 23;
ECCLESIASTICAL BODIES, 2, 3.
40. States; operation of Constitution on.
The Constitution and its limitations are the safeguards of all the States preventing any and all of them under the guise of license or otherwise from exercising powers not possessed. New York Life Ins. Co. v. Head, 149, 166.
CONSTRUCTION OF STATUTES.
1. Government; annulment for breach; assumption of benefit and burden of provision. The benefit and burden of a provision in a Government contract giv- ing a right to annul in consequence of a breach by failure to com- mence work must hang together and the Government cannot avail of the former without accepting the latter. Stone & Gravel Co. v. United States, 270.
2. Government; reletting on breach; damages to which Government entitled. Where the contract contains a provision for a method of annulment and
liquidated damages in case of a breach by failure to commence work and the Government avails of that provision it is only en- titled to the liquidated damages and cannot recover damages for difference in cost on reletting the contract under a provision for failure to complete or abandonment after commencing the work. United States v. O'Brien, 220 U. S. 321, distinguished. Ib.
3. Government; reletting; liability of original contractor. Where, after default of the original contractor, the contract is relet, the original contractor is not bound for difference unless the con- tract as relet is the same as the original contract. United States v. Axman, 36.
4. Government; reletting; variations; liability of original contractor. Where a contract for dredging requires the dredged material to be de- posited in a specified location, changes made as to the location for depositing such materials amount to such an important variation that the first contractor cannot be held for difference. United States v. McMullen, 222 U. S. 460, distinguished. Ib.
5. Government; changes in; importance of.
Change in location for depositing material dredged under a govern-
ment contract is not to be regarded as a minor change; it is clearly an important one. Ib.
6. Government; District of Columbia; obligation of surety on bond; dual aspect; change in contract; effect on liability of surety.
The obligation given by the surety under the District of Columbia Materialmen's Act of 1899 which is modeled after the General Materialmen's Act of 1894, has a dual aspect, being given not only to secure the Government the faithful performance of all the obliga- tions assumed towards it by the contractor, but also to protect third persons from whom the contractor may obtain materials and labor; these two agreements being as distinct as though contained in separate instruments, the surety cannot claim exemption from liability to persons supplying materials merely on account of changes made by the Government and the contractor without its knowledge and which do not alter the general character of the work. United States v. National Surety Co., 92 Fed. Rep. 549, approved. Equitable Surety Co. v. McMillan, 448.
7. Government; bond, discharge of surety by alteration of contract; when rule of strictissimi juris not applicable.
Under the rule of strictissimi juris, the agreement altering the contract must be participated in by the obligee or creditor as well as the principal in order to discharge the surety; in the case of a bond under the Materialmen's Acts of 1894 or 1899, there is no single obligee or creditor to consent thereto and the rule of strictissimi juris does not apply where the alterations agreed upon do not change the general nature of the work. Ib.
8. Government; District of Columbia; bond given under act of 1899; effect of change in contract to release surety.
In this case the alterations of the terms of a contract for building a school house in the District of Columbia altering its location but without affecting its general character, without the knowledge or consent of the surety, did not have the effect of releasing the surety from the obligation of the bond given under the District of Colum- bia Materialmen's Act of February 28, 1899. Ib.
9. Government; District of Columbia; bond; change in contract releasing surety; quære.
Quare, and not involved in this case, what would be the result of a change not contemplated in the original contract as between the District of Columbia and so great as to amount to abandonment of the contract? Ib.
10. Liquidated damages for delay; enforcement; waiver. While reasonable contracts for liquidated damages for delay are not to be regarded as penalties and may be enforced between the par- ties, Sun Printing Ass'n v. Moore, 183 U. S. 642, one party must not prevent the other party from completing the work in time, and if such is the case, even if the subsequent delay is the fault of the latter, the original contract cannot be insisted upon and the liquidated damages are waived. United States v. United Engineer- ing Co., 236.
11. Liquidated damages for delay; right of Government to recover; effect of supplemental contracts.
Where the original contract for government work provided for liq- uidated damages for delay beyond a specified date but supple- mental contracts contained no fixed rule for the time of completion, the Government is limited in its recovery to the actual damages sustained by reason of the delay for which the contractor was re- sponsible. Ib.
12. Liquidated damages for delay; fault of both parties; effect to annul obligation to pay.
It is the English rule, as well as the rule in some of the States, that where both parties are responsible for delays beyond the fixed date, the obligation for liquidated damages is annulled; and, unless there was a provision substituting a new date, the recovery for subse- quent delay is limited to the actual loss sustained. Ib.
13. Liquidated damages for delay; waiver by Government; effect of diffi- culty in proof of actual damages.
Where the Government has by its own fault prevented performance of the contract and thereby waived the stipulation as to liquidated damages, it cannot insist upon it as a rule of damages because it may be impracticable to prove actual damages. Ib.
See CLAIMS AGAINST UNITED STATES, 2;
CONSTITUTIONAL LAW, 10, 23, 36;
ECCLESIASTICAL BODIES, 2, 3;
PUBLIC LANDS, 10, 11, 12; PUBLIC WORKs, 3;
RESTRAINT OF TRADE, 1;
CONTROVERSIES BETWEEN STATES.
CONVEYANCES.
See INDIANS, 1, 2;
« ПретходнаНастави » |